Alice And Rabbit Hole Essays - Kingdom Hearts Characters

Alice And Rabbit Hole Like Alice tumbling down the rabbit hole, we don't know where things will lead us. Perpetually falling, landing, trying t claw our way up the slick metallic walls only to lose our grips and fall back into the blackness, on our way back to wonderland. But sadly we never quit get there. I wonder to myself. What are we getting accomplished? Why live just to die? And why do things go so drastically wrong, and then again maybe there not. In this man made and mechanized new wonderland there are now a lot more rabbit holes than the one Alice followed the little white rabbit down. They just come in different shades now. Like different flavors of candy. Inside the hole lies a world full of surprises. Some not every one is truly ready for. But since the technology of our time is, some venture into the strangeness without a clue on what they will find there. Some enter with out the intent on coming out. But don't make it as far down as they would like. Finding them self in a limbo between reality, and an endless wood. But why when you get down to wonderland do you come back forgetting the adventure that you had? Because the machine of modern life can't allow you to remember what has been discovered. Leaving you craving what you once held like a dodo bird croquet stick. "It was all very well to say `Drink me,' but the wise little Alice was not going to do that in a hurry. `No, I'll look first,' she said, `and see whether it's marked "poison" or not'." That bottle that one said "drink me" has been tosses aside for the mushroom and a bottle that says "Budweiser". Thankfully the bottle not marked "poison" or we might remember what's killing us. The mushroom no longer makes you taller than a tree, but it will make you feel that way and now that's all that matters. Wonderland will never get that back. Now a days we let the house of cards fall on us and hope for the "magic" at the bottom of the bottle to help us feel tall again Now people have found ways into wonderland, which were to be forbidden to man. But the binary key has decoded secretes of old. Instead of the white rabbit, the blinking mouse on the computer screen leads the way to wonderland. Information in ones and zeros has been dormant in the forest for only the caterpillar to blow in his smoke, is being spied on by Cheshire cats with Macintosh looking glasses. Sadly the world-wide-web does not have a www.wonderland.com address to take them all to the rabbit's house. The information that should only be over heard during a mad tea party has been infiltrated by a web cam. It must be in the mouse's teapot. Unfortunately, you will never see what the March Hare has found through that lens. Perhaps you need a different looking glass. Holes once restricted to responsible individuals like Indian Shaman have been exploited and widened enough that the ignorant and the naive have stumbled in. Natural stimulants used by holly men of ancient cultures to find the knowledge to heal are now a chemical escape route from reality. Natures keyhole that used to lock away secretes have been pried open by addiction and false hope. Following the leader like oysters following a walrus with a cigar, run around in a caucus race and in a cloud of dependence. The Mushrooms hardly have the same effects as it did on the girl in the blue dress. But then she did not buy them in a plastic bag in the girl's bathroom. The tea on the table is not 70 proof but in wonderland you don't need the drugs to be on the insane side. That why they live in wonderland. What the endless forests of wonderland possess are thing that should be known only to the jaberwalkie and the walrus and the carpenter. Once protected by the fermious bandersnach. The possessions are now being persuaded by Tweeldle Dee and Tweedle Dumb. Countless false Alice's have tripped into the open holes but all come out empty handed. With nothing more than memories that can only expanded away as dreams. The thing that we all search so vigorously for is simple. But it can't be found in wonderland. Disappearing like a striped cat that can stand on his head. Happiness in not to be point

The relevancy of the heartland - hinterland distinction in Canadas economic geography

The relevancy of the heartland - hinterland distinction in Canadas economic geography Until the early 20th century, Canada was primarily an agricultural nation. Since then it has become one of the most highly industrialized countries in the world as a direct result of the development of the 'heartland'. To a large extent the manufacturing industries present in the heartland are supplied with raw materials produced by the agricultural, mining, forestry, and fishing sectors of the Canadian economy, a region known as the 'hinterland'. The 'heartland-hinterland' concept in Canada describes patterns of economic power, namely, where economic power and control resides within the nation. Thus, the heartland-hinterland concept distinguishes raw-material and staple-producing hinterlands from the capital service industrial heartland and reveals the metropolis or dominating city of the system. At a national scale, the Canadian metropolis is Toronto, and the region with the most influence is the Great Lakes-St. Lawrence Lowlands. But while immense influence radiates outward from t he metropolis located in the heartland, the relationship between hinterland and heartland is one of intimate mutual dependency.The flags of Canada and the United States of Ameri...In modern Canadian economics, neither region can exist without each other, and the well-being of one directly affects the other. These two regions show remarkable contrasts, yet they are to a large extent interdependent on each other, clearly suggesting that the heartland-hinterland distinction is quite relevant in terms of Canada's economic geography.Upon discussing the importance of the heartland-hinterland in Canada, it is necessary to discuss what each term refers to. According to McCann the heartland is an area '... which possesses favourable physical qualities and grant food accessibility to markets; they display a diversified profile of secondary, tertiary, and quaternary industries; they are characterized by a highly urbanized and concentrated population which participates in a well-integrated urba n system; they are well advanced along the development path and possess the capacity for innovative change.'...

Choose a topic Research Paper Example | Topics and Well Written Essays - 500 words - 1

Choose a topic - Research Paper Example long-term capital investments.  As many companies require credit and loans from banks to sustain the  business practice so if the payments are not made then the businesses tend to fail (Baily & Elliott, 2013). An individual gets affected of US Financial market crashes. It affects an individual as companies suffer losses, and they reduce benefits like health care and insurance. Moreover, due to low-income people will not be able save as they need to meet  daily expenses (Baily & Elliott, 2013). Answer 2: Primary role of Federal Reserve System is to provide the citizens of United States with a safer, flexible, as well as stable flow of monetary benefits. In the current economic condition, they have effectively participated reducing unemployment by introducing large-scale intervention that created money for them. The role of Federal Reserve Chairman is to protect the economy of United States against inflation and determine businesses in order to boost the economy, testifying twice a year and steering the FED to solve financial matter through consensus. In order to protect economic environment, the chairman of Federal Reserve can make monetary policy, supporting the economy by checking inflation. The role of Federal Reserve Board has the main role to devise U.S monetary policy and making key decisions at Federal Open Market Committee (FOMC). With respect to current economic condition, the board supervises the banking performances that affects the economy and most importantly as President of United States need to take approval from the board relating to financial, agricultural or industrial interests so they require to carry out effective decisions (Alessi & Sergie, 2013). Answer 3: The interest rates have an affect the United States when the prices in the Federal Reserve Board are fluctuated. Interest rate is basically the charges the lender take for lending money if there is lower interest rate people will have more money spend creating a ripple effect through

Thesis driven essay Example | Topics and Well Written Essays - 750 words - 2

Thesis driven - Essay Example Through the Allegory of the Cave, in his work The Republic, Plato describes the position of unenlightened man, and 24 centuries later, the main hero of Wachowski Brothers’ movie The Matrix, hacker Neo, makes his way from the Cave towards enlightenment. According to Plato, human is caved in his/ her regular and familiar environment. He/ she does not ask questions, and does not will to change own life in more real and true way. Despite the ever-present possibility to start those changes, which Plato vividly describes as a light from the ideal world behind one’s back, most of the humans prefer to keep living in their familiar world of illusions, which is only a poor projection, a shadow of the ideal world. Unenlightened and delusioned man is a prisoner of his/ her own illusions. In Wachowski Brothers’ movie, the Matrix is a platform for humans’ illusions. Morpheus describes it as â€Å"the loading program†, â€Å"the construct for simulations† (The Matrix). Most of the people live in a common simulation, which is determined by AI. As Plato predicted, a more powerful â€Å"brain†, AI, had excelled human’s intelligence, and because the machine has no notion of morality, AI uses humankind brutally, but rationally for own benefit. The image of a caved unenlightened man is almost literally illustrated in the movie, especially in the scene, where Neo wakes up in a capsule and find himself to be a caved, but in a rather modern and more technical way. He is a part of high-technical mechanism, where Plato’s chains are cables and leads. They chain Neo’s whole body, but what’s the most important, they chain Neo’s brain. The familiar environment looks dark and grey now, and very similar to the Cave. Morpheus says, this darkness was made by humans (The Matrix). To get free from AI control, and to get out of the capsule, Neo symbolically bursts those cables and leads, and find himself confused and

Contemporary Marketing Research - John Lewis bucking the trend on the Essay

Contemporary Marketing Research - John Lewis bucking the trend on the UK High Street - Essay Example This study would be focused on evaluating the performance of John Lewis in previous years and the marketing strategies adapted by the retailer in order to enhance its sales. Similarly, the marketing strategies for the forthcoming years would also be evaluated to identify the performance and productivity of the company in the worrying time of 2013. This study would highlight the reasons for the exceptional performance of the retailer that is not even in the top 4 retailers in UK i.e. John Lewis. Furthermore, the impact of the adapted marketing strategies on the performance of the company would be evaluated. This would help to identify the remarkable performance of the company in the market. In the end, recommendations would be provided for the retail company i.e. John Lewis, in order to enhance its sales and revenues in the industry and to gain competitive advantage over other competitors in the market. This would help the company to enhance its performance which will eventually lead to increase in sales and revenues. The year 2012 was a nightmare for the retailers in United Kingdom. The retail growth in this particular year was just 1.2 percent. This retail growth could be said as the third lowest growth rate in the last 40 years (The Telegraph, 2012). The economic crisis and the recession after 2008 are the core reason for such downturn in the retail industry (O’Donnell, 2011). Due to such recession, it has been observed that the Jessops; one of the retailers in High Streets, has closed down all of its retail stores in the UK due to which almost 1370 people lost their job (BBC News, 2013a). Retail industry in UK is being directly influenced by the growing competition from supermarkets and internet retailers. This is one of the major reasons for the closure of Jessops in UK as the company was not able to cope with the changing trends in the retail industry. With advancement in the technology, the retail industry is moving towards

Causes of Variation in Construction Projects

Causes of Variation in Construction Projects Literature reviews that of Variations and Variation Orders requires a comprehensive understanding of the root causes of Variations (Hester et al., 1991).Variations some of which are financial, design aesthetics, changes in drawings, weather, geological and geotechnical reasons. From the literature review, there were 53 causes of Variations identified and these Variations are mainly caused by the Employer, Consultants and Contractors. As shown in Figure 1, these causes of Variations were grouped under four categories: Employer related Variations, Consultants related Variations, Contractor related Variations and other Variations. These Causes of Variations have been identified by many researchers (CII, 1990a; Thomas and Napolitan, 1994; Clough and Sears, 1994; Fisk, 1997; Ibbs et al., 1998; OBrien, 1998; Mokhtar et al., 2000; Gray and Hughes, 2001; Arain et al., 2004). The causes of Variations can be categorized according to the originators (CII, 1990a; Thomas and Napolitan, 1994). The 53 causes identified from the literature review are also discussed below. A. Employer Related Changes This section discusses the causes of variations that were initiated by the Employer. In some cases, the Employer directly initiates Variations or the Variations are required because the Employer fails to fulfil certain requirements for carrying out the project. Change of plans or scope by Employer: Change of plan or scope of project is one of the most significant causes of Variations in construction projects (CII, 1990b) and is usually the result of insufficient planning at the project planning stage, or also i can because of lack of involvement of the Employer in the design phase (Arain et al., 2004). This cause the Variations affects the project severely during the later phases. Change of schedule by Employer: A change of schedule or master programme during the project construction phase may result in major resource reallocation (Fisk, 1997; OBrien, 1998). This is because time has an equivalent money value. A change in schedule means that the Contractor will either provide additional resources, or keep some resources idle in the construction site. In both cases additional cost is incurred. Employers financial problems: The Employer of the project may run into difficult financial situations that force him to make changes in an attempt to reduce cost of the project. Employers financial problems affect project progress and quality (Clough and Sears, 1994; OBrien, 1998). Proper financial planning and review of project cash flow would be effective in avoid this problem to from happening. Inadequate project objectives: Inadequate project objectives are one of the causes of Variations in construction projects (Ibbs and Allen, 1995). Due to inadequate project objectives, the designers would not be able to develop a comprehensive design which leads to many of Variations during the project construction phase. Replacement of materials or procedures: Replacement of materials or procedures may cause major Variations during the construction phase. The substitution of procedures includes Variations in application methods (Chappell and Willis, 1996). Therefore, an adjustment to the original contract value is required if there is a change in procedures. Impediment in prompt decision making process: Prompt decision making is an important factor for project success (Sanvido et al., 1992; Gray and Hughes, 2001). A delay in decision making may obstruct the progress of subsequent construction activities and that may eventually delay the entire project progress. Obstinate nature of Employer: A building project is the result of the combined efforts of the professionals. They have to work at the various interfaces of a project (Wang, 2000; Arain et al., 2004). If the Employer is obstinate, he may not accommodate other creative and beneficial ideas. Eventually, this may cause major Variations in the later stages and affect the project negatively. Change in specifications by owner: Changes in specifications are frequent in construction projects with inadequate project objectives (OBrien, 1998). In a multi-player environment like any construction project, change in specifications by the Employer during the construction phase may require major Variations and adjustments in project planning and procurement activities. B. Consultant Related Variations This section discusses the causes of Variations that were initiated by the consultant. In some cases, the consultant directly initiates Variations or the Variations are required because the consultant fails to fulfil certain requirements for carrying out the project. Change in design by Consultants: Change in design for improvement by the Consultant is a norm in contemporary professional practice (Arain et al., 2004). The changes in design are frequent in projects where construction starts before the design is finalized (Fisk, 1997). Design changes can affect a project adversely depending on the timing of the occurrence of the changes. Errors and omissions in design: Errors and omissions in design are an important cause of project to delays (Arain et al., 2004). Design errors and omissions may lead to loss of productivity and delay in project schedule (Assaf et al., 1995). Hence, errors and omissions in design can affect a project adversely depending on the timing of the occurrence of the errors. Conflicts between contract documents: Conflict between contract documents can result in misinterpretation of the actual requirement of a project (CII, 1986a). To convey complete project scope for participants, the contract documents must be clear and straight to the point. Insufficient details in contract documents may adversely affect the project, leading to delay in project completion. Inadequate scope of work for contractor: In a multi-player environment like construction, the scope of work for all the players must be clear and without uncertainty for successful project completion (Fisk, 1997; Arain et al., 2004). Inadequate scope of work for the contractor can cause major Variations that may negatively affect the project, and leads to changes in construction planning. Technology change: Technology change is a potential cause of Variations in a project. Project planning should be flexible for accommodating new beneficial Variations (CII, 1994b). This is because the new technology can be beneficial in the project life cycle, for instance, reducing maintenance cost of the project. Or new methods of constructions that reduce construction cost. Value engineering: Value engineering should ideally be carried out during the design phase (DellIsola, 1982). During the construction phase, value engineering can be a costly exercise, as Variation in any design element would initiate and leads to Variations to other relevant design components (Mokhtar et al., 2000). Lack of coordination: A lack of coordination between parties may cause major variations that could eventually impact the project adversely (Arain et al., 2004). Unfavourable Variations, which affect the projects negatively, can usually be managed at an early stage by paying extra focus in coordination. Design complexity: Complex designs require unique skills and construction methods (Arain et al., 2004). Complexity affects the flow of construction activities, whereas simple and linear construction works are relatively easy to handle (Fisk, 1997). Hence, complexity may cause major Variations in construction projects. Inadequate working drawing details: To convey a complete concept of the project design, the working drawings must be clear and concise (Geok, 2002). Insufficient working drawing details can result in misinterpretation of the actual requirement of a project (Arain et al., 2004). Thorough reviewing of design details would assist in minimizing Variations. Inadequate shop drawing details: Shop drawings are usually developed for construction work details for site professionals (Cox and Hamilton, 1995). As mentioned earlier with regard to working drawing details, likewise, inadequacy of shop drawing details can be a potential cause of Variations in the construction projects. Consultants lack of judgment and experience: Professional experience and judgment is an important factor for a successful completion of a building project (Clough and Sears, 1994; OBrien, 1998). The lack of professional experience increases the risk of errors in design as well as during construction. Eventually, this may affect the project quality and delay the project completion. Lack of consultants knowledge of available materials and equipment: Knowledge of available materials and equipment is an important factor for developing a comprehensive design (Geok, 2002). In the construction industry where material standardization is not common, the consultants lack of knowledge of available materials and equipment can cause numerous major Variations during various project phases. Honest wrong beliefs of consultant: Honest wrong beliefs may cause construction professionals to contribute poor value add in projects (Arain, 2002; Arain et al., 2004). Consultants, without having firsthand knowledge, may make decisions based on their wrong beliefs which would adversely affect the pace of the project. Consultants lack of required data: A lack of data can result in misinterpretation of the actual requirements of a project (Assaf et al., 1995; Arain, 2002). When there is insufficient data, consultants are prone to develop designs based on their own perceptions, which may not be what the Employer wants. Eventually, this may cause major Variations and affect the project negatively. Obstinate nature of consultant: In a multi-player environment like construction, the professionals have to work as team at the various interfaces of a project (Wang, 2000; Arain et al., 2004). If the consultant is obstinate, he may not accommodate other creative and beneficial ideas. Eventually, this may cause major Variations in the later stages and affect the project Negatively. Ambiguous design details: A clearer design tends to be comprehended more readily (OBrien, 1998). Ambiguity or Doubtfulness or uncertainty in design is a potential cause of Variations in a project. This is because ambiguity in design can be misinterpreted by project participants, leading to rework and delay in the project completion. Eventually, this may affect the project progress negatively. Design discrepancies (inadequate design): Inadequate design can be a frequent cause of Variations in construction projects (CII, 1990a; Fisk, 1997). Design discrepancies affect the project functionality and quality. Eventually, this can affect a project adversely depending on the timing of the occurrence of the Variations. Noncompliance of design with government regulations: Noncompliance of design with government regulations or policies would cost the project difficult to execute (Clough and Sears, 1994). Noncompliance with government regulations may affect the project safety and progress negatively, leading to serious accidents and delays in the project completion. Noncompliance of design with owners requirements: A comprehensive design is one that accommodates the owners requirements (Cox and Hamilton, 1995). A noncompliance design with the owners requirements is considered an inadequate design (Fisk, 1997). Eventually, this may cause Variations for accommodating the Employers requirements. This may affect the project adversely during the construction phase. Change in specifications by consultant: Changes in specifications are frequent in construction projects with inadequate project objectives (OBrien, 1998). As mentioned earlier with respect to changes in specifications by the Employer, this is also a potential cause of Variations in a project, leading to reworks and delays in the project completion. C. Contractor Related Variations This section discusses the causes of Variations that were related to the Contractor. In some cases, the contractor may suggest Variations to the project, or the Variations may be required because the contractor fails to fulfil certain requirements for carrying out the project. Lack of Contractors involvement in design: Involvement of the Contractor in the design may assist in developing better designs by accommodating his creative and practical ideas (Arain et al., 2004). Lack of Contractors involvement in design may eventually cause Variations. Practical ideas which are not accommodated during the design phase will eventually affect the project negatively. Unavailability of equipment: Unavailability of equipment is a procurement problem that can affect the project completion (OBrien, 1998). Occasionally, the lack of equipment may cause major design Variations or adjustments to project scheduling to accommodate the replacement. Unavailability of skills (shortage of skilled manpower): Skilled manpower is one of the major resources required for complex technological projects (Arain et al., 2004). Shortage of skilled manpower is more likely to occur in complex technological projects. This lack can be a cause for Variations that may delay the projects completion date. Contractors financial difficulties: Construction is a labour intensive industry. Whether the Contractor has been paid or not, the wages of the worker must still be paid (Thomas and Napolitan, 1994). Contractors financial difficulties may cause major Variations during a project, affecting its quality and progress and in some cases even the safety of the site is affected if there is an argument. Contractors desired profitability: Contractors desired profitability can be a potential cause of Variations in construction projects. This is because Variations are considered a common source of additional works for the contractor (OBrien, 1998). The Contractor may eventually strive to convince the project Employer to allow certain Variations, leading to additional financial benefits for him. Differing site conditions: Differing site condition can be an important cause of delays in large building projects (Assaf et al., 1995). The contractor may face different soil conditions than those indicated in the tender documents. Eventually this may affect his cost estimates and schedule negatively. Defective workmanship: Defective workmanship may lead to demolition and rework in construction projects (Fisk, 1997; OBrien, 1998). Defective workmanship results in low quality in construction projects (Arain et al., 2004). Even the Contractor bares the cost of the defective work, but this also may affect the project negatively, leading to rework and delay in the project completion. Unfamiliarity with local conditions: Familiarity with local conditions is an important factor for the successful completion of a construction project (Clough and Sears, 1994). If the Contractor is not aware of local conditions, it would be extremely difficult for him to carry out the project. Eventually, project delays may occur that end up with vital Variations in the entire design entity. Lack of a specialized construction manager: The construction manager carries out the construction phase in an organized way to eliminate the risks of delays and other problems. Lack of a specialized construction manager may lead to defective workmanship and delay in the construction project. Fast track construction: Fast track construction requires an organized system to concurrently carry out interdependent project activities (Fisk, 1997). When the public and private sectors have large funds and want to complete projects in a very short time, complete construction drawings and specifications may not be available when the contractor starts work (Arain et al., 2004).Eventually, this procurement mode may cause major Variations. Poor procurement process: Procurement delays have various negative effects on other processes in the construction cycle (Fisk, 1997). Occasionally, the procurement delay may cause an entire change or replacement for originally specified materials or equipment for the project (Arain et al., 2004). This may therefore cause a need for project activities to be reworked. Lack of communication: Detrimental Variations, which affect the projects adversely, can usually be managed at an early stage with strong and incessant communication. A lack of coordination and communication between parties may cause major Variations that could eventually impact the project negatively (Arain et al., 2004). Contractors lack of judgment and experience: The consultants lack of professional experience increases the risk of errors during construction (OBrien, 1998). This lack may cause major construction Variations in a project, when both Contractor and consultant could not identify or foresee the problems in the planning stage due to both parties are lacking of experience. Eventually, this may affect the project quality and delay the project completion. Long lead procurement: Procurement delays have various adverse affects on other processes in the construction cycle (Fisk, 1997). Occasionally, the procurement delay may cause an entire change or replacement for originally specified materials or equipment for the project. Delay in long lead procurement is a common cause of delays in building projects (Assaf et al., 1995). Honest wrong beliefs of contractor: As mentioned earlier with respect to honest wrong beliefs of the consultant, honest wrong beliefs of the contractor can also be a potential cause of Variations in construction projects. Contractors, without having firsthand knowledge, may make decisions based on their wrong beliefs which would adversely affect the quality and pace of the project. Complex design and technology: Complex design and technology require detailed interpretations by the designer to make it comprehensible for the Contractor (Arain, 2002). A complex design may be experienced for the first time by the Contractor. Eventually, the complexity may affect the flow of construction activities, leading to delays in the project completion. Lack of strategic planning: Proper strategic planning is an important factor for successful completion of a building project (Clough and Sears, 1994; CII, 1994a). The lack of strategic planning is a common cause of Variations in projects where construction starts before the design is finalized, for instance, in concurrent design and construction contracts (OBrien, 1998). Contractors lack of required data: A lack of required data may affect the contractors strategic planning for successful project completion, leading to frequent disruptions during the construction process. This is because a lack of data can result in misinterpretation of the actual requirements of a project (Assaf et al., 1995; Arain et al., 2004). Contractors obstinate nature: As mentioned earlier with regard to the obstinate nature of consultant, likewise, this can be a potential cause of Variations in construction projects. If the Contractor is obstinate, he may not accommodate creative and beneficial ideas suggested by others. Eventually, this may cause major Variations in the later stages and affect the project negatively. D. Other Variations This section discusses the causes of Variations that were not directly related to the project team. Weather conditions: Adverse weather conditions can affect outside activities in construction projects (Fisk, 1997; OBrien, 1998). When weather conditions vary such as the various monsoon seasons in Malaysia, the contractor needs to adjust the construction schedule accordingly. Occasionally, this may affect the project progress negatively, leading to delays in construction. Safety considerations: Safety is an important factor for the successful completion of a building project (Clough and Sears, 1994). Noncompliance with safety requirements may cause major Variations in design. Lack of safety considerations may affect the project progress negatively, leading to serious accidents and delays in the project completion. Change in government regulations: Local authorities may have specific codes and regulations that need to be accommodated in the design (Arain et al., 2004). Change in government regulations during the project construction phase may cause major Variations in design and construction. This can affect a project negatively depending on the timing of the occurrence of the changes. Change in economic conditions: Economic conditions are one of the influential factors that may affect a construction project (Fisk, 1997). The economic situation of a country can affect the whole construction industry and its participants. Eventually, this may affect the project negatively, depending on the timing of the occurrence of the Variations. Socio-cultural factors: Professionals with different socio-cultural backgrounds may encounter problems due to different perceptions, and this may affect the working environment of the construction project (Arain et al., 2004). Lack of coordination is common between professionals with different socio-cultural backgrounds (OBrien, 1998). Eventually, project delays may occur that end up with vital changes in the entire project team. Unforeseen problems: Unforeseen conditions are usually faced by professionals in the construction industry (Clough and Sears, 1994; OBrien, 1998). If these conditions are not solved as soon as possible, they may cause major Variations in the construction projects. Eventually, this may affect the project negatively, leading to reworks and delays in the project completion.

The Prime of Miss Jean Brodie by Muriel Spark Essay -- Education Educa

The Prime of Miss Jean Brodie by Muriel Spark Miss Brodie fails to be a good teacher because she teaches on her own accord, gives her students wrong impressions, and displays unprofessional behavior towards her staff and pupils. As a schoolteacher in Edinburgh during the 1930’s there were many rules and regulations that teachers had to adhere to in order to successfully feed the minds of their young pupils. Schoolteachers had more of a responsibility during this period than today because school was the only source of information and education that people could receive. Due to this fact, the government set strict policies and curriculums (and still do) that teachers must follow so that students could grow up to become well round individuals. Miss Brodie seemed to side step, insult or simply ignore some of the curriculum that was given, and teach her students on her own conditions. An example of this is when Miss Brodie is telling the girls that she and Miss MacKay have a radical difference in their principals of education. Miss Brodie has told Miss MacKay that the girls will be equipped with the necessary information needed to pass the end of term exams. After she says this to the headmistress, Miss Br odie says to the girls:   Ã‚  Ã‚  Ã‚  Ã‚  I trust you girls to work hard and try to scrape through (the exams), even if you learn the stuff and forget it the next day. This statement is telling the girls that she does not believe in the required curriculum and she wouldn’t care if they have forgot it after their exams. She only wants the girls to study of these exams so that she can have an excuse to boast to Miss MacKay, seeing the girls do well in them is not her primary concern. Another example of Miss Brodie teaching on her own accord was her lesson under the Elm tree where she told her students about her holiday in Egypt. It is evident that Miss Brodie is pretending to teach her students but trying to make it quit believable for all who look upon her shaded class when she says to her students: Hold up your books, prop them up in you hands, in case of any intruders, we are doing out history lesson†¦our poetry†¦English grammar. Although Miss Brodie’s lessons were somewhat educational and her students learnt new concepts and ideas, the schools during that time would not allow â€Å"freestyle teaching† because it made the students too reprehensive. By sett... ...f lust with Mr. Lloyd only creates a poor image for the students to have of her. Miss Brodie’s hostility toward Miss MacKay also demonstrates her inability to maintain a professional manner. She is constantly telling her students indirectly the she does not like Miss MacKay through various tactics. When Miss Brodie lashes out to Miss Mackay for trying to make her resign, she makes matters worse for herself because is only creates more tension and frustration between the two teachers. Miss Brodie unprofessional manner and inability to maintain her lust gives good reason for why she is a poor teacher. As a person, Miss Brodie does have many positive qualities that she seems to have used in the classroom. Her students did take interest in her teaching, but only because they were so different from what they were used to. Miss Brodie was a very smart and well-traveled woman, which was another positive aspect that she brought to her classroom. However her inability to teach the given curriculum, giving her students wrong impressions, and her numerous affairs and arguments with the staff leads one to believe that even though Miss Brodie was in her prime, she was still a poor teacher.